Work Order Authorization - Reliable Jet Maintenance Page 2

ADVERTISEMENT

ADDITIONAL TERMS AND CONDITIONS OF WORK AUTHORIZATION
1.
Representation of Authority.
(d)
Owner shall be obligated to pay interest on all amounts not
paid when due at the rate of one and one-half percent (1.5%) per
Owner (as identified in the Work Authorization) hereby
month (eighteen percent (18%) per annum).
represents to Reliable Jet Maintenance, LLC (“RJM”) that if either
owns the aircraft described in the Work Authorization (the
5.
Limited Exclusive Warranty and Waiver of Damages.
“Aircraft”) or is the authorized by the owner of such aircraft to enter
into the Work Authorization.
(a)
RJM hereby warrants that the Services performed
pursuant to this Agreement shall be free of defects in workmanship
2.
Scope of Services, Rates.
for a period of sixty (60) days after the redelivery of the Aircraft by
RJM to Owner.
(a)
RJM shall accomplish the maintenance services
requested by Customer of the Work Authorization and as otherwise
(b)
The foregoing warranty (the “Limited Warranty”)
authorized by Owner and accepted by RJM (the “Services”). RJM
is confined only to the workmanship of RJM, and does not extend to
shall have the right to subcontract to other qualified repair or
a warranty of the quality or fitness of any parts, components or
overhaul facilities the performance of part or all of the Services.
equipment manufactured by any entity other than RJM, in regard to
(b)
The rates and charges for labor and parts provided
such parts, its sole and exclusive remedy and right to recovery shall
by RJM and by third party suppliers shall be set forth in, as
be against the subject manufacturer or supplier.
applicable, the Work Authorization, any supplemental Work
Authorization Form signed by parties, or as otherwise agreed.
(c)
The Limited Warranty provided above by RJM is
Absent a specific agreement establishing the amounts of rates and
conditioned upon (i) Owner providing to RJM (at the address first set
charges, RJM and Owner agree that such amounts shall be equal to
for the forth above, attention: Manager) written notice specifying the
RJM’s standard rates and charges.
purported defect in workmanship; and (ii) Owner, within thirty (30)
days after providing such written notice RJM, delivering the Aircraft
3.
Delivery: Unavoidable Delays.
(or the pertinent portion thereof) to RJM for correction of the
purported defect in workmanship.
(a)
Unless otherwise provided in the Work
Authorization, the execution of the Work Authorization shall
(d)
Warranty claims shall be excluded when the
evidence the delivery of the Aircraft by Owner to RJM for the
Aircraft has been exposed or subjected to any of the following (i) any
performance of the Services (the “Delivery”).
maintenance, repair, installation, storage, operation, or the use which
(b)
At the Delivery of the Aircraft to RJM, Owner shall
is improper or otherwise not in compliance with the manufacturer’s
provide to RJM complete and accurate information, specifications
instructions or applicable law or regulations; (ii) any alteration,
and documents relevant to the Aircraft as requested by RJM,
modification or repair by anyone other than RJM without RJM’s
including, without limitation, log books and maintenance records.
prior written consent, which shall not be unreasonably withheld; or
(c)
RJM shall not be liable for delay or failure in the
(iii) any accident, foreign object damage, misuse, improper storage,
performance, in whole or part, of the Services if such failure is
neglect, or negligence after the redelivery of the Aircraft to Owner.
caused by public enemy fire, flood, strikes, or other labor disputes
(whether at RJM’s facility or elsewhere), riots, insurrection, war,
(c) THE WARRANTIES, OBLIGATIONS AND
governmental orders or actions, failure of transportation, delays
LIBILITIES OF RJM AND REMEDIES OF OWNER SET
occasioned by suppliers or subcontractors, or any other cause beyond
FORTH IN THIS SECTION ARE EXCLUSIVE AND IN
the control of RJM not specifically mentioned herein.
SUBSTITUTION FOR, AND OTHER WARRANTIES,
OBLIGATIONS, LIBILITIES, RIGHTS, CLAIMS AND
4.
Payment: Redelivery: Interest.
REMEDIES, EXPRESS OR IMPLIED WITH RESPECT TO
ANY NON-CONFORMANCE OR DEFECT IN THE
(a)
Owner shall make full payment to RJM in United
AIRCRAFT, INCLUDING BUT NOT LIMITED TO (i) ANY
States Dollars, of all amounts owing by owner as a result of the
IMPLIED WARRANTY OF MERCHANTABILITY OR
performance of the Services.
FITNESS AND (ii) ANY IMPLIED WARRANTY ARISING
(b)
Unless RJM and Owner expressly agree otherwise
FROM COURSE PERFORMANCE OR COURSE OF
in the Work Authorization, all amounts owing by Owner to RJM
DEALING OR USAGE OF TRADE.
shall be due and payable upon the completion of the Services and a
condition of the redelivery of the Aircraft to Owner.
6.
Controlling Law: Jurisdiction: Attorney’s Fees.
(c)
RJM shall have the option of allowing Owner to
take such redelivery prior to Owner making full payment for the
(a)
The rights of the parties pursuant to the Work
Services; provided, however, that the Owner’s right to delay making
Authorization shall be governed by the Laws of the State of Florida.
full payment until after redelivery is conditioned upon (i) RJM
expressly agreeing in the Work Authorization to allow such delayed
(b)
Any suit, action or proceeding brought by RJM or
payment and (ii) the agreement that under no circumstances shall full
by Owner arising out of or relating to the Services shall be brought
payment be delayed beyond (10) days after the redelivery of the
exclusively in either the courts of the State of Florida, County of
Aircraft, RJM may file a lien claim against the Aircraft to ensure the
Palm Beach, or the United States District Court of Florida entitled to
fulfillment of the Owner’s repayment obligations.
an award of its reasonable attorney’s fees and expenses incurred in
connection therewith.

ADVERTISEMENT

00 votes

Related Articles

Related forms

Related Categories

Parent category: Business
Go
Page of 2